Loading...
Effective date: January 1, 2026
By using the website located at www.abileneconcretecontractor.org or by engaging Abilene Concrete for any concrete contracting services, you agree to be bound by these Terms and Conditions. If you do not agree to any part of these terms, do not use this website or engage our services.
Abilene Concrete is a concrete contractor based in Abilene, TX, providing residential and commercial concrete services including but not limited to driveways, patios, sidewalks, foundations, retaining walls, pool decks, and related work. Services are delivered at job sites across West and Central Texas. The scope of any specific project is defined in a written estimate or contract provided before work begins.
All estimates provided by Abilene Concrete are free of charge and require an on-site visit to be binding. Phone or online estimate figures are approximations only and may change after a site assessment.
Written estimates are valid for 30 days from the date issued. After 30 days, material costs or labor availability may require a revised quote. An estimate does not constitute a binding contract until both parties have signed a written agreement.
Prices are subject to change if the scope of work changes after the estimate is accepted. Any change orders must be agreed upon in writing before additional work is performed.
Scheduling is confirmed once a written agreement is signed and any required deposit is received. Start dates are estimates and may be affected by weather, material availability, or permit processing times. We will notify you as soon as possible if a start date needs to change.
If you need to cancel or postpone a scheduled project, please contact us at least 5 business days before the scheduled start date. Cancellations made with less notice may result in a forfeiture of any deposit paid, as materials may already have been ordered and crew time allocated.
Abilene Concrete reserves the right to reschedule work due to weather conditions that would compromise concrete quality, such as extreme heat, freezing temperatures, or rain during a pour. We will communicate rescheduled dates promptly.
Payment terms are outlined in the written agreement for each project. Typically, a deposit is required to secure your spot on the schedule, with the balance due upon substantial completion of the work. Specific payment milestones for larger projects will be defined in the contract.
Accepted payment methods will be specified in your agreement. Invoices not paid within the terms stated in the agreement may be subject to a late fee or may result in suspension of work until the balance is brought current.
If a dispute arises over an invoice, contact us within 10 days of the invoice date. We will work with you in good faith to resolve the issue before any further collection steps are taken.
Abilene Concrete will identify and obtain required building permits for projects where permits are legally necessary, unless otherwise agreed in writing. Permit fees are typically passed through to the client at cost and will be itemized in the estimate. The client is responsible for ensuring that HOA approvals or other private approvals are obtained before work begins.
Abilene Concrete warrants that all work will be performed in a workmanlike manner consistent with industry standards for concrete construction in Texas. Specific warranty terms will be stated in the written agreement for each project.
Concrete is a natural material that can develop hairline cracks as it cures and as soil conditions change over time. Minor cracking that does not affect the structural integrity or drainage of the slab is a normal characteristic of concrete and is not covered under workmanship warranties.
Warranty coverage does not apply to damage caused by client misuse, unauthorized modifications, extreme weather events, or conditions that were not disclosed at the time of the site assessment.
Before work begins, the client is responsible for:
Abilene Concrete is not responsible for damage to underground utilities that were not disclosed or marked prior to excavation.
To the fullest extent permitted by applicable law, Abilene Concrete shall not be liable for any indirect, incidental, special, or consequential damages arising out of or related to the services provided, including but not limited to loss of use, loss of income, or property damage beyond the scope of the contracted work.
In any event, the maximum liability of Abilene Concrete for any claim arising from a specific project shall not exceed the total amount paid by the client for that project.
Before initiating any formal dispute process, both parties agree to make a good-faith effort to resolve disagreements directly. You may contact us at team@abileneconcretecontractor.org or (325) 283-1159.
If a dispute cannot be resolved informally, the parties agree to submit to binding arbitration in TX before initiating any litigation, except where injunctive relief is required to prevent immediate harm.
These Terms and Conditions are governed by and construed in accordance with the laws of the State of Texas, without regard to its conflict of law provisions. Any disputes that proceed to litigation shall be filed exclusively in the courts of Taylor County, Texas.
The content on www.abileneconcretecontractor.org is provided for informational purposes only. While we make every effort to keep information accurate and current, we make no warranties, express or implied, regarding the completeness, accuracy, or fitness for any particular purpose of the content. Use of this website is at your own risk.
Abilene Concrete reserves the right to update or modify these Terms and Conditions at any time. Changes will take effect upon posting to this page, and the effective date will be updated at the top. Your continued use of this website or engagement of our services after changes are posted constitutes acceptance of the updated terms.
Questions about these terms may be directed to:
Abilene Concrete
510 Walnut St, Abilene, TX 79601
Email: team@abileneconcretecontractor.org
Phone: (325) 283-1159